Article Date: 04/07/2008

LOST PRODUCTION EFFICIENCY NOT SHOWN BY GOVERNMENT DELAY

Armed Services Board of Contract Appeals

Appeal of Fox Construction, Inc.

No. 55266
March 5, 2008

Overview

The Armed Services Board of Contract Appeals has ruled that a contractor did not experience compensable, government-caused delay. And, because the contractor’s claim for lost production efficiency was based on its extended stay at the job site, that claim failed as well.

Background

The ... Log in to view the full text.

NOT YET A SUBSCRIBER?

Purchase a Subscription
with a money-back guarantee
and immediate access

Already a member?

Email: REQUIRED

Password: REQUIRED

Forgot your password? Click here to have your password emailed to you.